Crick Law Firm

Suspension of Work Clause

Generally, construction contracts include a suspension of work clause which provides that the government may suspend, interrupt, or delay work for the convenience of the government.

A government delay is compensable if:

  1. It is unreasonable;
  2. The Contracting Officer orders it;
  3. The contractor has not caused the suspension by its own or its subcontractors’ negligence or failure to perform; and
  4. The cost of performance increases.

The contractor may be entitled to recover delay costs even if it finishes work on time, so long as the contractor proves that it planned to finish the work early but was delayed by the government.

A contractor may also raise government delay as a defense to a liquidated damages assessment or a default termination.

If both the contractor and the government contribute to a delay, and the causes of delay are intertwined such that the periods and costs of delay cannot be apportioned clearly, then neither party can recover for delay.

Profit is not recoverable under the suspension of work clause; only costs are recoverable.

The content and information provided on this website is for informational purposes only and is not legal advice. The presentation of this information is not intended to create, and your receipt of it does not constitute, an attorney-client relationship. The content and information provided is intended for general information only and may or may not reflect the most current developments in the law. Although these materials may be prepared by legal professionals, they should not be used as a substitute for professional services. By using this website you are expressly agreeing that there is no attorney-client relationship between you and ROBERT CRICK LAW FIRM, PLLC. If you have a question regarding a particular legal issue or need legal advice, please contact ROBERT CRICK LAW FIRM, PLLC.
Super Lawyers is a registered trademark of Thomson Reuters. Martindale-Hubbell® is the facilitator of a peer review rating process. Ratings reflect the anonymous opinions of members of the bar and the judiciary. Martindale-Hubbell® PEER REVIEW RATINGS™ fall into two categories - legal ability and general ethical standards.  For more information, see  AV® PreeminentTM is a certification mark of Reed Elsevier Properties, Inc., used in accordance with the Martindale-Hubbell certification procedures, standards, and policies. Any link to other websites are not intended to be referrals or endorsements of those sites. The links provided are maintained by the providing entities and they are solely responsible for the content of their own sites. The opinions or viewpoints expressed herein do not necessarily reflect those of ROBERT CRICK LAW FIRM, PLLC.